In the absence of a formal written contract, contractor still held liable for additional financing costs resulting from delays
Introduction
In the recent case
of Barkby Real Estate Developments
Limited v Cornerstone Telecommunications
Infrastructure Limited [2022] EWHC
1892 (TCC), the English Technology and Construction Court (the “Court”) held a contractor liable to its
employer for failing to complete its works within a “reasonable time” pursuant
to section 14 of the Supply of Goods and Services Act 1982.
Background
Cornerstone Telecommunications Infrastructure Limited (“Cornerstone”) was engaged by Barkby
Real Estate Developments Limited (“BREDL”)
to assist with the removal, replacement and relocation of a mobile telephone
mast at a development at Bexhill Road, Hastings (the “Development”). However, only email quotation was sent by
Cornerstone and no formal written contract was entered into between the
parties.
Cornerstone finalised its original foundation design for the mast relocation
at end of March 2019, but Cornerstone was required to re-design the foundation
as a result of inadequate ground conditions discovered only after works had
commenced on site. The ground conditions issue resulted in a delay to completion of Cornerstone’s works
of about five months. Cornerstone eventually completed its works and achieved practical
completion of the Development on 7 August 2020.
BREDL claimed that the Development would have been completed and handed
over to its purchaser, Hastings Borough Council by 30 June 2020, but for
Cornerstone’s delay in completing its works. As a result, BREDL sought recovery
of finance costs and other losses resulted from the alleged delay in handover
of the Development.
Decision
The terms of
Cornerstone’s contract with BREDL
Although there was no formal written contract
between the parties, the Court held that a binding contract was formed on 5
September 2019, when Cornerstone acknowledged receipt of BREDL’s payment. In the absence of an
express term as to the time for completion of contract, section 14 of the Supply of Goods and Services Act 1982 implied that the supplier will
carry out the service within a reasonable time. However, what
is a reasonable time will depend on the facts of each case.
Did Cornerstone fail to carry out and
complete its works within a reasonable time?
The Court was satisfied that had it not
been for that 5-month delay, Cornerstone would have completed its works by
about the end of March 2020. As to the responsibility of the ground condition
issue, having considered the expert evidence, the Court agreed with BREDL that
a competent designer would have arranged for a geotechnical survey to be
carried out before Cornerstone finalised the foundation design. Since Cornerstone
did not do this, the design produced by Cornerstone was held to be inadequate.
As a result, Cornerstone had to re-design the foundations which
ultimately delayed its works. In support of its finding that Cornerstone had
failed to carry out its works within a reasonable time, the Court also has
taken into account the following:-
·
Cornerstone had not offered any
explanation as to why it took an additional five months
to resolve the problems identified with its initial foundation design.
·
Cornerstone further compounded
the delays by allocating the ordered mast to another site while allowing the
contract for supply of fibre to lapse.
·
Cornerstone had failed to give
appropriate priority to the project, which affected the progress of work.
On the facts of this case, the Court was
satisfied that Cornerstone had failed to complete its works within a
reasonable time.
Was BREDL entitled to recover the
finance costs,
and if so, in what amount and are these too remote?
As to BREDL’s claim for additional project
finance cost, the Court was satisfied that as a result of the delayed sale of
the Development, BREDL was unable to redeem a loan within the expected timeframe,
which had resulted in additional fees and interest. Cornerstone contended that
the loss was too remote to be recoverable.
In deciding
whether the loss claimed is too remote, the Court reiterated the following
legal principles from Attorney General
of the Virgin Islands v Global Water Associates Ltd [2020] UKPC 18;
[2021] AC 23:-
1.
To be recoverable, the type of loss must have been reasonably
contemplated as a serious possibility.
2.
What was reasonably contemplated depends upon the knowledge which the
parties possessed at that time or, in any event, which the party, who later
commits the breach, then possessed.
3.
The test to be applied is an objective one.
The Court ruled that Cornerstone
was aware of the time constraint of the project and the timely completion of
its works would have a direct impact on BREDL achieving completion of the main
development. Accordingly, “it was held
that Cornerstone knew, or should have appreciated, that this was a main
development where the build period was relatively short, needed the mast
removed for its satisfactory completion and that it was being sold on to
Hastings Borough Council.”
Having ruled that Cornerstone was responsible
for the delays, the Court found that BREDL was entitled to recover most of its
additional financing costs and all of its additional management costs. These
losses would not have been incurred had Cornerstone completed its works on
time.
On the other hand, the Court rejected
Cornerstone’s submission that these losses were too remote. Indeed, so long as it
is in Cornerstone’s contemplation that there was a serious possibility that
BREDL’s ability to pay off its financing was tied to practical completion
(including Cornerstone’s works) of the project, that is sufficient. Knowledge
of the precise details about BREDL’s financial arrangement is not necessary
Hong Kong
Court’s approach
Similar to the English court’s approach, in the absence of an express
term in the contract, section 6 of the Supply of Services (Implied Terms)
Ordinance (Cap. 457) will imply into a contract a term that the “supplier will carry out the service within a
reasonable time”. In Approach
Industries Ltd v S & P Auto Ltd [2012] HKCU 1559 (unreported, DCCJ
1638/2008, 27 July 2012), there was a 7-month delay for the installation of a
supercharger, but the Hong Kong court found no breach as the plaintiff was
unable to adduce evidence as to what was “reasonable time”, and on the other
hand there was evidence by the defendant that missing/unfit parts resulted in
the installation work taking more time to complete. In essence, what is a
reasonable time will always turn on the facts of the case. It will be for the
plaintiff to provide evidence as to what is regarded as “reasonable time” in
that particular case.
Takeaway
The above English decision serves as a reminder to contractors that in
the absence of a formal contract, they are still likely to be under an implied
obligation to complete their works within a reasonable time, and undue delays
may render them liable for damages for breach of contract. Furthermore, contractors
should also consider and be familiar with the objective of project to assess
the serious possibility of loss to
the employer that may arise due to the contractors’ delays to the completion to
the project.
For enquiries,
please feel free to contact us at: |
E: construction@onc.hk T: (852) 2810
1212 19th Floor, Three Exchange Square, 8 Connaught
Place, Central, Hong Kong |
Important: The law and procedure on
this subject are very specialised and
complicated. This article is just a very general outline for reference and
cannot be relied upon as legal advice in any individual case. If any advice
or assistance is needed, please contact our solicitors. |
Published by ONC Lawyers © 2022 |